1. Home
  2. Browse Decisions
  3. A.3d
  4. 121 A.3d
  5. 121 A.3d 593 (2015)
 

JOHN SPEARLY CONST. v. PENNS VALLEY AREA

No. 2050 C.D. 2014

121 A.3d 593 (2015)

JOHN SPEARLY CONSTRUCTION, INC. v. PENNS VALLEY AREA SCHOOL DISTRICT, Appellant.

Commonwealth Court of Pennsylvania.

Decided July 24, 2015.

Attorney(s) appearing for the Case

Joseph P. Green , Bellefonte, for appellee.

BEFORE: ROBERT SIMPSON, Judge, and P. KEVIN BROBSON, Judge, and JAMES GARDNER COLINS, Senior Judge.

OPINION BY Judge SIMPSON.

In this construction contract appeal, the Penns Valley Area School District (District) asks whether the Centre County Court of Common Pleas (trial court)1 erred in granting the contract claim of John Spearly Construction, Inc. (Contractor), and denying its claim for liquidated damages. The District withheld partial payment from Contractor based on a delay in substantial completion of the work and...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases