Plaintiff, a contractor retained by the City of New York in 1990 to rebuild a bridge in Long Island City, sought delay damages allegedly caused by the defendant public utility companies' failure to timely move a gas main and telephone conduits after receiving notice from plaintiff that those facilities were impeding progress. While it is undisputed that public utilities have a long-standing common-law and statutory "obligation to move their facilities when they interfere...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.