1. Home
  2. Browse Decisions
  3. N.J.
  4. 180 N.J.
  5. 180 N.J. Super. 350 (1981)
 

BROADWAY MAINT. CORP. v. RUTGERS

180 N.J. Super. 350 (1981)

434 A.2d 1125

BROADWAY MAINTENANCE CORPORATION, PLAINTIFF-APPELLANT, v. RUTGERS, THE STATE UNIVERSITY, DEFENDANT-RESPONDENT. EDWIN J. DOBSON, JR., INC., PLAINTIFF-APPELLANT, v. RUTGERS, THE STATE UNIVERSITY, DEFENDANT-RESPONDENT.

Superior Court of New Jersey, Appellate Division.

Decided August 10, 1981.

Attorney(s) appearing for the Case

Charles H. Hoens, Jr. argued the cause for appellant Broadway Maintenance Corporation (Lum, Biunno & Tompkins, attorneys; Dennis J. Drasco and David C. Dreifuss, on the brief).

Julius L. Schapira, a member of the New York Bar (Greenberg, Trayman, Cantor, Reiss & Blasky) argued the cause for appellant Edwin J. Dobson, Jr., Inc. (Wilentz, Goldman & Spitzer, attorneys; Mr. Schapira, Jerome Reiss, Sharon Wirkus and Richard R. Bonamo, members of the New York Bar, on the brief).

Eugene J. Sullivan, Assistant Attorney General, argued the cause for respondent Rutgers, The State University (James R. Zazzali, Attorney General of New Jersey, attorney; John J. Degnan, former Attorney General of New Jersey; Mr. Sullivan and Mary C. O'Connell, Deputy Attorney General, on the brief).

Before Judges BISCHOFF, MILMED and FRANCIS.

PER CURIAM.

Plaintiffs Broadway Maintenance Corporation (Broadway) and Edwin J. Dobson, Jr., Inc. (Dobson), appeal from separate final judgments that in part dismissed certain claims plaintiffs asserted against Rutgers, The State University (Rutgers). The controversy arose over the construction of Rutgers Medical School, a proposed two-year project that ran about 25 months behind schedule. Broadway and Dobson claimed that Rutgers was responsible for this delay. The...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases