HARRIS, Justice.
Plaintiff, an electrical contractor, agreed to a "no-damage" clause in a contract with the defendant Iowa department of transportation (the department). There were extensive delays in the project which for two years prevented plaintiff from performing. Notwithstanding the contractual no-damage provision, plaintiff brought this suit on the theory that the delays here were not of the kind contemplated by the parties when they made the contract. We think...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.