AFFIRMED.
GOODWIN, J.
The plaintiff entered into a written agreement to build a hotel for the defendant for $6,920,316.00. Thereafter the plaintiff sued to terminate the agreement on the ground that the defendant had unreasonably delayed the plaintiff in its performance. From a decree denying relief, the plaintiff appeals.
Shortly after the written contract was executed, both parties learned that certain steel, not previously contemplated by the architects...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.