1. Home
  2. Browse Decisions
  3. F.Supp.
  4. 60 F.Supp.
  5. 60 F.Supp. 644 (1945)
 

J. C. RIDNOUR CO. v. UNITED STATES

No. 44741.

60 F.Supp. 644 (1945)

J. C. RIDNOUR CO. v. UNITED STATES.

Court of Claims.

June 4, 1945.

Attorney(s) appearing for the Case

David A. Fegan, of Washington, D. C. (Morris, Kix-Miller & Baar, of Washington, D. C., on the brief), for plaintiff.

James J. Sweeney, of Washington, D. C., and Francis M. Shea, Asst. Atty. Gen., for defendant.

Before WHALEY, C. J., and MADDEN, LITTLETON, JONES, and WHITAKER, JJ.

WHITAKER, Judge.

Plaintiff sues for liquidated damages deducted for delays in furnishing blue denim working jumpers. Plaintiff says they were unlawfully deducted because the delays were caused, first, by a delay in the delivery to it of the material out of which the jumpers were to be made, and that this was caused by an ice storm, which it says was one of the "unforeseeable" causes of delay for which the contractor was not to be charged with liquidated damages; and...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases