1. Home
  2. Browse Decisions
  3. F.Supp.
  4. 35 F.Supp.
  5. 35 F.Supp. 332 (1940)
 

ANTHONY P. MILLER, INC. v. NEEDHAM

Civ. No. 92.

35 F.Supp. 332 (1940)

ANTHONY P. MILLER, Inc., v. NEEDHAM et al.

District Court, E. D. Pennsylvania.

September 9, 1940.

Attorney(s) appearing for the Case

Edward H. Cushman, of Philadelphia, Pa., and Thomas H. Munyan, of Atlantic City, N.J., for plaintiff.

Lewis M. Stevens and Joseph A. Byrne, Jr., both of Philadelphia, Pa., for defendants.

KIRKPATRICK, District Judge.

This is a suit by a general contractor upon three surety bonds, given by a subcontractor, one of the defendants, with the Bonding Company, the other defendants, as surety, for damages to the plaintiff by reason of the subcontractor's delay and inefficiency in prosecuting the work, his failure to complete the work, and his failure to pay material bills in a substantial amount.

The case...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases